News & Analysis as of

Federal Contractors › Breach of Contract › Construction Project

Gordon Rees Scully Mansukhani

May 2025 Government Contracts Legal Update and Podcast

Gordon Rees Scully Mansukhani on

Gordon Rees Scully Mansukhani presents the latest insights from our Government Contracts group, offering a comprehensive overview of recent significant decisions, regulatory changes, and essential updates for businesses...more

Troutman Pepper Locke

Court of Federal Claim Rejects Spearin Claim and Holds Contractor Responsible for Failure to Prevent Mold Growth

Troutman Pepper Locke on

James Talcott Construction, Inc. v. United States, No. 14-427 C, 2019 BL 72711, at *1 (Fed. Cl. Mar. 4, 2019) - In May of 2010, the United States, acting through the Department of Defense (the “Government”) awarded a...more

Bradley Arant Boult Cummings LLP

A Warning for Government Contractors: Sovereign Immunity

Bradley Arant Boult Cummings LLP on

A recent Georgia appellate court decision serves as a stark reminder to contractors on government projects that sovereign immunity, though frequently disclaimed in the contract, may limit a contractor’s ability to recover. In...more

Troutman Pepper Locke

Federal Court Holds That Under Louisiana Law, Actual Notice Of Cause Of Delay Satisfies Contractual Notice Requirement Despite...

Troutman Pepper Locke on

Parkcrest Builders, LLC v. Hous. Auth. of New Orleans, 2017 U.S. Dist. LEXIS 125012 (E.D. La. August 8, 2017) - The Housing Authority of New Orleans (“the Authority”) contracted with Parkcrest Builders, LLC (“Parkcrest”)...more

Troutman Pepper Locke

D.C. Federal Court Declines to Enjoin Arbitration Because the Arbitrator Could Issue Any Equitable Relief Required, the Integrity...

Troutman Pepper Locke on

TK Servs., Inc. v. RWD Consulting, LLC, 2017 U.S. Dist. Lexis 97239 (D.D.C., June 23, 2017) - This litigation arose from a dispute between TK Services, Inc. (“TKS”), as sub-subcontractor, and RWD Consulting, LLC (“RWD”),...more

Troutman Pepper Locke

You Cannot Have it Both Ways: Missouri Appellate Court Holds City Cannot Bring a Complaint for Breach of a Contract and Plead in...

Troutman Pepper Locke on

City of Dardenne Prairie v. Adams Concrete & Masonry, LLC, No. ED104982, 2017 Mo. App. LEXIS 533 (Mo. Ct. App. May 30, 2017) - This case arises out of a construction project in which the City of Dardenne Prairie (the...more

Troutman Pepper Locke

Texas Court of Appeals Holds That Owner’s Change to Contractor’s Means and Methods Resulted in a “Breach,” Instead of a “Change”...

Troutman Pepper Locke on

Port of Houston Auth. of Harris Cnty. v. Zachry Constr. Corp., 2016 Tex. App. LEXIS 13306 (Tex. App. Houston 14th Dist. Dec. 15, 2016) - This contract dispute dates back to 2004, when the Port of Houston Authority...more

Bradley Arant Boult Cummings LLP

Contractor Barred from Using the “Total Cost” or “Modified Total Cost” Approach to Establish Delay Claim

Bradley Arant Boult Cummings LLP on

In a recent ruling, Hill York Service Corporation v. Critchfield Mechanical, Inc., the U.S. District Court for the Southern District of Florida held that a contractor may not establish damages for delay under either the...more

8 Results
 / 
View per page
Page: of 1

"My best business intelligence, in one easy email…"

Your first step to building a free, personalized, morning email brief covering pertinent authors and topics on JD Supra:
Sign up Log in
*By using the service, you signify your acceptance of JD Supra's Privacy Policy.
- hide
- hide